Aluminum Blanks

Wat de aanbestedende dienst vraagt

SV0102-27 Aluminum Blanks Solicitation Posting: 10/23/2026 Questions Deadline: 11/6/2026 8AM EST Proposal Deadline: 11/13/2026 2PM EST Contract: 2 Year, Firm Fixed Price, IDIQ, EPA EPA Index: PCU331315331315 Aluminum Sheet, Plate, and Foil Manufacturing. Small Business Set Aside: 100% Submissions Email: Wesley Newell, Contract Specialist, wesley.newell2@usdoj.gov Delivery Terms: FOB Destination to Unicor, 14601 Burbridge Rd, Cumberland, MD, 21502. PART I: INFORMATION This is a combined synopsis/solicitation for commercial items prepared in accordance with the format in Subpart 12.6 as supplemented with additional information included in this notice. This announcement constitutes the only solicitation; offers are being requested and a written solicitation will not be issued. The solicitation number is SV0102-26 and this solicitation is issued as a Request For Quote (RFQ). The North American Industry Classification System code is 331315 Aluminum Sheet, Plate and Foil Manufacturing (small business size 1,400). This requirement is 100% set-aside for small business; small business size standard for this solicitation is 1,400 employees. UNICOR, Federal Prison Industries, Inc., intends to enter into a two (2)-year, firm-fixed-price, indefinite delivery-indefinite quantity contract for the following commercial item(s): Line 1 SBL0127A ALUM-BLANK,10INX7IN,.040-THK,CAUTION* 50,000 EA ALUM-.040X2.5X15-C.YEL/C.YEL-MASK-SQ-CNR Line 2 SBL0133 ALUM,BLNK,.032"X4-1/2"X5",YELLOW 20,000 EA ALUM-.040X2.5X15-C.YEL/C.YEL-MASK-SQ-CNR Line 3 SBL0128 .032"X2-1/2"X15",RECTANGLE,ALUMINUM, 1,000 EA ALUM-.040X2.5X15-C.YEL/C.YEL-MASK-SQ-CNR Guaranteed contract minimum is 40,000 EA. Minimum delivery order is 4,000 ft or $10,520. Maximum delivery order is 10,000 ft or $26,300. Offers must include the following: Solicitation: ________ SV102-27 Aluminum Blanks___________ Company Name: ______________________________________ Company Address: ____________________________________ SAM Unique Entity Identifier (UEI): ______________________ Business Size: (Large or Small): ___________________________ Company Point of Contact: _______________________________ Telephone number: _____________________________________ Email Address: ________________________________________ Line-Item Pricing: Line 1: ___________; Lead Time: ___________ Line-Item Pricing: Line 2: ___________; Lead Time: ___________ Line-Item Pricing: Line 3: ___________; Lead Time: ___________ Technical Descriptions of Items Offered Country of Origination: __________________________________ Rolled/Manufactured in USA: (Yes / No) Warranty:______________________________________________ Acknowledgement of Any Amendments Posted to SAM.gov. Three Business Management Questionnaires for past performance. Delivery schedule will be established at time of award. Delivery orders will be issued in accordance with 52.216-19. By submission of an offer, the Offeror acknowledges the requirement that a prospective awardee shall be registered in the SAM database (System Award Management) prior to submitting a proposal, during performance and through final payment of any contract resulting from this solicitation. Commercial Goods Evaluation Factors: Technical specifications, price, past performance, and delivery time. Technical and past performance, when combined, are: More important than price. NOTICE TO GOVERNMENT WHEN CONTRACTOR(S) DELAYS: In the event the contractor(s) encounter difficulty in meeting performance requirements, or when there is an anticipated difficulty in complying with the delivery terms or completion dates, or whenever the contractor has knowledge that any actual or potential situation is delaying or threatens to delay the timely delivery/performance of this contract, the contractor must immediately notify the Field Administrative Contracting Officers at UNICOR Cumberland or in writing, giving pertinent details. This information will not be construed as a waiver by the Government of the required delivery…

Taal van deze aankondiging: English. Titel en beschrijving tonen we precies zoals de aanbestedende dienst ze heeft gepubliceerd.

How this compares

• This is one of 907 open tenders in Verenigde Staten for Structuren en materialen voor de bouw; ondersteunende producten voor de bouw (uitgezonderd elektrische apparatuur).
• Bidders were given 29 days from publication to the deadline; the median for open tenders in Verenigde Staten is 21 days.

More open tenders from this buyer

Similar open tenders